truCX

Glossary of Terms

Last revised: Jan 01, 2024

truCX Glossary of Terms

“Access Credentials” means any user name, identification number, password, license or security key, security token, PIN, or other security code, method, technology, or device, used alone or in combination, to verify an individual’s identity and authorization
to access and use the Services.

“Action” means any claim, action, cause of action, demand, lawsuit, arbitration, inquiry, audit, notice of violation, proceeding, litigation, citation, summons, subpoena, or investigation of any nature, civil, criminal, administrative, regulatory, or
other, whether at law, in equity, or otherwise.

“Affiliate” of a Person means any other Person that directly or indirectly, through one or more intermediaries, controls, is controlled by, or is under common control with, such Person.

“Agreement” means the legal contract between Provider and Customer which incorporates this Glossary of Terms by reference which may include, without limitation any Software as a Service Agreement.

“Authorized Users” means Customer’s employees, consultants, contractors, and agents (a) who are authorized by Customer to access and use the Services under the rights granted to Customer pursuant to this Agreement; and (b) for whom access to the Services
has been purchased hereunder.

“Available” means the Services are available for access and use by Customer and its Authorized Users over the Internet.

“Confidential Information” means information in any form or medium (whether oral, written, electronic, or other) that the Disclosing Party considers confidential or proprietary, including information consisting of or relating to the Disclosing Party’s
technology, trade secrets, know-how, business operations, plans, strategies, customers, source code, and pricing, and information with respect to which the Disclosing Party has contractual or other confidentiality obligations, in each case whether
or not marked, designated, or otherwise identified as “confidential”.

“Customer” means the Person designated as such in the applicable Agreement preamble.

“Customer Data” means information, data, and other content, in any form or medium, that is collected, downloaded, or otherwise received, directly or indirectly, from Customer or an Authorized User by or through the Services or that incorporates or is
derived from the Processing of such information, data, or content by or through the Services. For the avoidance of doubt, Customer Data does not include Resultant Data or any other information reflecting the access or use of the Services by or on
behalf of Customer or any Authorized User.

“Customer Failure” means any delay or failure of performance caused in whole or in part by Customer’s delay in performing, or failure to perform, any of its obligations under the applicable Agreement.

“Customer Systems” means the Customer’s information technology infrastructure, including computers, software, hardware, databases, electronic systems (including database management systems), and networks, whether operated directly by Customer or through
the use of third-party services.

“Disclosing Party” means a party to an Agreement disclosing Confidential Information.

“Documentation” means any manuals, instructions, or other documents or materials that the Provider provides or makes available to Customer in any form or medium and which describe the functionality, components, features, or requirements of the Services
or Provider Materials, including any aspect of the installation, configuration, integration, operation, use, support, or maintenance thereof.

“Effective Date” is the date specified as the “Effective Date” in the applicable Agreement preamble.

“Force Majeure Event” means any circumstances beyond Provider’s reasonable control including (without limitation): (i) acts of God; (ii) flood, fire, earthquake, public health emergencies or explosion; (iii) war, invasion, hostilities (whether war is
declared or not), terrorist threats or acts, riot or other civil unrest; (iv) government order, law, or actions; (v) embargoes or blockades; (vi) national or regional emergency; (vii) strikes, labor stoppages or slowdowns, or other industrial disturbances;
and (viii) shortage of adequate power or transportation facilities.

“Harmful Code” means any software, hardware, or other technology, device, or means, including any virus, worm, malware, or other malicious computer code, the purpose or effect of which is to (a) permit unauthorized access to, or to destroy, disrupt, disable,
distort, or otherwise harm or impede in any manner any (i) computer, software, firmware, hardware, system, or network; or (ii) any application or function of any of the foregoing or the security, integrity, confidentiality, or use of any data Processed
thereby; or (b) prevent Customer or any Authorized User from accessing or using the Services or Provider Systems as intended by this Agreement. Harmful Code does not include any Provider Disabling Device.

“Intellectual Property Rights” means any and all registered and unregistered rights granted, applied for, or otherwise now or hereafter in existence under or related to any patent, copyright, trademark, trade secret, database protection, or other intellectual
property rights laws, and all similar or equivalent rights or forms of protection, in any part of the world.

“Law” means any statute, law, ordinance, regulation, rule, code, order, constitution, treaty, common law, judgment, decree, or other requirement of any federal, state, local, or foreign government or political subdivision thereof, or any arbitrator, court,
or tribunal of competent jurisdiction.

“Losses” means any and all losses, damages, deficiencies, claims, actions, judgments, settlements, interest, awards, penalties, fines, costs, or expenses of whatever kind, including reasonable attorneys’ fees and the costs of enforcing any right to indemnification
hereunder and the cost of pursuing any insurance providers.

“Person” means an individual, corporation, partnership, joint venture, limited liability entity, governmental authority, unincorporated organization, trust, association, or other entity.

“Platform” means the Microsoft Azure and Power platform or any similar service utilized by Provider.

“Platform SLA” means the applicable service level agreement offered from time to time in connection with the Platform.

“Process” means to take any action or perform any operation or set of operations that the SaaS Services are capable of taking or performing on any data, information, or other content, including to collect, receive, input, upload, download, record, reproduce,
store, organize, compile, combine, log, catalog, cross-reference, manage, maintain, copy, adapt, alter, translate, or make other derivative works or improvements, process, retrieve, output, consult, use, perform, display, disseminate, transmit, submit,
post, transfer, disclose, or otherwise provide or make available, or block, erase, or destroy. “Processing” and “Processed” have correlative meanings.

“Provider” means truCX, LLC, a Pennsylvania limited liability company, its successors and assigns.

“Provider Disabling Device” means any software, hardware, or other technology, device, or means (including any back door, time bomb, time out, drop dead device, software routine, or other disabling device) used by Provider or its designee to disable Customer’s
or any Authorized User’s access to or use of the Services automatically with the passage of time or under the positive control of Provider or its designee.

“Provider Indemnitee” means Provider, its Affiliates, and each of their respective officers, directors, employees, managers, owners, agents, successors, and assigns.

“Provider Materials” means the Services, Documentation, and Provider Systems and any and all other information, data, documents, materials, works, and other content, devices, methods, processes, hardware, software, and other technologies and inventions,
including any deliverables, technical or functional descriptions, requirements, plans, or reports, that are provided or used by Provider or any Subcontractor in connection with the Services or otherwise comprise or relate to the Services or Provider
Systems. For the avoidance of doubt, Provider Materials include Resultant Data and any information, data, or other content derived from Provider’s monitoring of Customer’s access to or use of the Services, but do not include Customer Data.

“Provider Personnel” means all individuals involved in the performance of Services as employees, agents, or independent contractors of Provider or any Subcontractor.

“Provider Systems” means the information technology infrastructure used by or on behalf of Provider in performing the Services, including all computers, software, hardware, databases, electronic systems (including database management systems), and networks,
whether operated directly by Provider or through the use of third-party services.

“Receiving Party” means a party to an Agreement receiving Confidential Information.

“Representatives” means, with respect to a party, that party’s and its Affiliates’ employees, officers, directors, consultants, agents, independent contractors, service providers, sublicensees, subcontractors, and legal advisors.

“Resultant Data” means data and information related to Customer’s use of the Services that is used by Provider in an aggregate and anonymized manner, including to compile statistical and performance information related to the provision and operation of
the Services.

“Scheduled Downtime” means all scheduled outages of the Services.

“Services” means the services described in Exhibit A to the applicable Agreement.

“Territory” means the United States of America.

“Third-Party Materials” means materials and information, in any form or medium, including any open-source or other software, documents, data, content, specifications, products, equipment, or components of or relating to the Services that are not proprietary
to Provider.

It’s reinvention that’s designed for you. And it starts here.